LA County Solicitations

Solicitation Detail

Solicitation Number:

LACDA20-004

Title:

Single Family Home Improvement Loan Program

Department:

LA County Development Authority

Bid Type:

Commodity / Service

Bid Amount:

N/A

Commodity:

HOME CONSTRUCTION SERVICE, SINGLE FAMILY

Description:

To download this solicitation package, please go to or visit the Community Development Commission of the County of Los Angeles website: www.lacdc.org and click on “Doing Business With Us,” and View Open Solicitations.” January 2, 2020 NOTICE REQUEST FOR QUOTES FOR SINGLE FAMILY HOME IMPROVEMENT PROGRAM RFQ NO. LACDA20-004 Notice is hereby given that quotes will be received by the Los Angeles County Development Authority (the LACDA) until Thursday, January 16, 2020, at 3:00 pm for Single Family Home Improvement Program. This will include furnishing all labor, material and equipment, and performing all work necessary and incidental in accordance with the Scope of Work (SOW) and contract documents. Bidders must attend a mandatory site visit at the following date, time and location: Thursday, January 9, 2020, at 11:00 AM Homeowner Name: Raymond and Renee Lopez Street Address: 10528 Bluefield Avenue City, State, ZIP: Whittier, CA Telephone: (562) 318-4806 A Request for Quotes (RFQ) solicitation package containing all submission requirements may be downloaded from the LACDA’s website at www.lacda.org, under “For Vendors – View Open Solicitations”. Bidders are advised that this RFQ is an informal solicitation, and should not be construed as engaging in a formal competitive bidding pursuant to any statute, ordinance, rule or regulation. Bidders shall provide their quote, all required forms, and documentation by the due date and time stated herein, and shall deliver it via regular mail or in person to: Lonii Prevost, Procurement Coordinator Los Angeles County Development Authority Housing Investment and Finance 700 W. Main St. Alhambra, CA 91801 All quotes shall be labeled “Quote for Single Family Home Improvement Program RFQ No. LACDA20-004, 1/16/2020”. Any Bidder who wishes his/her bid to be considered is responsible for making certain that it is received by the LACDA at the stated location and at the stated date and time. No oral, telephonic proposals, or modifications will be considered unless specified. Quotes received after the scheduled deadline will be returned unopened. Request for Quotes Single Family Home Improvement Program January 2, 2020 Page 2 Questions regarding the RFQ are to be directed to Lonii Prevost at (626) 586-1817 or Lonii.Prevost@lacda.org. Si usted requiere más información sobre este anuncio, por favor comuníquese con la Sra. Gabriela Martinez al siguiente numero de teléfono (626) 586-1840. In submitting a quote, each Bidder thereby agrees that, if awarded a contract, Bidder shall execute a standard agreement, a sample of which is attached to the RFQ package for reference. The LACDA shall not be obligated to facilitate an agreement between the homeowner and the contractor with any Bidder who refuses to execute said standard agreement. The LACDA reserves the right to reject any and all quotes. This RFQ is not a contract or commitment of any kind. The LACDA is not liable for costs incurred in the preparation of the respondent’s quote. It reserves the right to issue supplementary information or guidelines related to this RFQ. REQUIREMENTS: • Insurance Requirements (please refer to Section 9 – Insurance, of the sample Agreement) ? General Liability: shall include products/completed/on-going operations coverage, an additional insured endorsement providing coverage on a primary and noncontributory basis and a waiver of subrogation. ($2,000,000) ? Workers’ Compensation: shall be Statutory and include Employer’s Liability, and a waiver of subrogation. (1,000,000) ? Automobile Insurance: coverage shall include owned, hired, non-owned, OR any auto and a waiver of subrogation. ($50,000) ? Pollution Liability: Must include coverage for restoration, cleanup, liabilities and additional insured endorsement. ($1,000,000) ? Crime Insurance: the LACDA and their Agents shall be named as loss payee on such policy. ($10,000) ? Bonds: Contractor License Surety Bond • B-General Building Contractors California State License (please refer to https://www.classifications@cslb.ca.gov) ? “B” General Building Contractor license: must provide evidence of a valid B-1 General Contractor’s license issued by the Department of Consumer Affairs Contractors State License Board - https://www.cslb.ca.gov ? Contingent Upon Contractor Award – Licensed contractor must submit a Construction Schedule that includes a work-breakdown timeline, which provides a project start/finish date and a milestone date for each listed activity to be completed. Request for Quotes Single Family Home Improvement Program January 2, 2020 Page 3 • EPA Certification • PENALTY – (please refer to Section 12 – Penalty, of the Sample Agreement) ? Penalty: If the Work is not performed in accordance with the terms of this Agreement and in compliance with the Notice to Proceed, the LACDA is entitled to impose the Penalty of four hundred fifty dollars ($450) per for each day the work is delayed with respect to the contract. APPROVED BY: KeAndra Cylear Dodds, Manager Los Angeles County Development Authority

To download this solicitation package, please go to or visit the Community Development Commission of the County of Los Angeles website: www.lacdc.org and click on “Doing Business With Us,” and View Open Solicitations.”
January 2, 2020

NOTICE
REQUEST FOR QUOTES
FOR
SINGLE FAMILY HOME IMPROVEMENT PROGRAM
RFQ NO. LACDA20-004

Notice is hereby given that quotes will be received by the Los Angeles County Development Authority (the LACDA) until Thursday, January 16, 2020, at 3:00 pm for Single Family Home Improvement Program. This will include furnishing all labor, material and equipment, and performing all work necessary and incidental in accordance with the Scope of Work (SOW) and contract documents.

Bidders must attend a mandatory site visit at the following date, time and location:

Thursday, January 9, 2020, at 11:00 AM
Homeowner Name: Raymond and Renee Lopez
Street Address: 10528 Bluefield Avenue
City, State, ZIP: Whittier, CA
Telephone: (562) 318-4806

A Request for Quotes (RFQ) solicitation package containing all submission requirements may be downloaded from the LACDA’s website at www.lacda.org, under “For Vendors – View Open Solicitations”.

Bidders are advised that this RFQ is an informal solicitation, and should not be construed as engaging in a formal competitive bidding pursuant to any statute, ordinance, rule or regulation.

Bidders shall provide their quote, all required forms, and documentation by the due date and time stated herein, and shall deliver it via regular mail or in person to:

Lonii Prevost, Procurement Coordinator
Los Angeles County Development Authority
Housing Investment and Finance
700 W. Main St.
Alhambra, CA 91801

All quotes shall be labeled “Quote for Single Family Home Improvement Program RFQ No. LACDA20-004, 1/16/2020”. Any Bidder who wishes his/her bid to be considered is responsible for making certain that it is received by the LACDA at the stated location and at the stated date and time. No oral, telephonic proposals, or modifications will be considered unless specified. Quotes received after the scheduled deadline will be returned unopened.
Request for Quotes
Single Family Home Improvement Program
January 2, 2020
Page 2

Questions regarding the RFQ are to be directed to Lonii Prevost at (626) 586-1817 or Lonii.Prevost@lacda.org. Si usted requiere más información sobre este anuncio, por favor comuníquese con la Sra. Gabriela Martinez al siguiente numero de teléfono (626) 586-1840.

In submitting a quote, each Bidder thereby agrees that, if awarded a contract, Bidder shall execute a standard agreement, a sample of which is attached to the RFQ package for reference. The LACDA shall not be obligated to facilitate an agreement between the homeowner and the contractor with any Bidder who refuses to execute said standard agreement.

The LACDA reserves the right to reject any and all quotes. This RFQ is not a contract or commitment of any kind. The LACDA is not liable for costs incurred in the preparation of the respondent’s quote. It reserves the right to issue supplementary information or guidelines related to this RFQ.

REQUIREMENTS:

• Insurance Requirements (please refer to Section 9 – Insurance, of the sample Agreement)

? General Liability: shall include products/completed/on-going operations coverage, an additional insured endorsement providing coverage on a primary and noncontributory basis and a waiver of subrogation. ($2,000,000)
? Workers’ Compensation: shall be Statutory and include Employer’s Liability, and a waiver of subrogation. (1,000,000)
? Automobile Insurance: coverage shall include owned, hired, non-owned, OR any auto and a waiver of subrogation. ($50,000)
? Pollution Liability: Must include coverage for restoration, cleanup, liabilities and additional insured endorsement. ($1,000,000)
? Crime Insurance: the LACDA and their Agents shall be named as loss payee on such policy. ($10,000)
? Bonds: Contractor License Surety Bond

• B-General Building Contractors California State License (please refer to https://www.classifications@cslb.ca.gov)

? “B” General Building Contractor license: must provide evidence of a valid B-1 General Contractor’s license issued by the Department of Consumer Affairs Contractors State License Board - https://www.cslb.ca.gov
? Contingent Upon Contractor Award – Licensed contractor must submit a Construction Schedule that includes a work-breakdown timeline, which provides a project start/finish date and a milestone date for each listed activity to be completed.

Request for Quotes
Single Family Home Improvement Program
January 2, 2020
Page 3

• EPA Certification
• PENALTY – (please refer to Section 12 – Penalty, of the Sample Agreement)
? Penalty: If the Work is not performed in accordance with the terms of this Agreement and in compliance with the Notice to Proceed, the LACDA is entitled to impose the Penalty of four hundred fifty dollars ($450) per for each day the work is delayed with respect to the contract.

APPROVED BY:

KeAndra Cylear Dodds, Manager
Los Angeles County Development Authority

Open Day:

1/2/2020

Close Date:

1/16/2020 3:00:00 PM

Contact Name:

Lonii Prevost

Contact Phone:

(626) 586-1817

Contact Email:

Lonii.prevost@lacda.org

Last Changed On:

1/2/2020 7:21:28 PM

Attachment File (0) :

Click here to download attachment files.

File Name	Description	Type	Size	Last Update On
{{file.AttFileName}}	{{file.AttFileDesc}}	{{file.AttFileType}}	{{file.AttFileSize}}	{{file.LastUpdateDate.slice(6,-2)\|date: 'MM-dd-yyyy'}}

…
{{pageIndex+1}}
…

eCAPS PROCUREMENT HELP-DESK

Email:	eCAPS Procurement Team

Office Hours:	Monday-Friday
	8:00 am - 5:00 pm PST

Los Angeles County Solicitations